Get 20M+ Full-Text Papers For Less Than $1.50/day. Start a 14-Day Trial for You or Your Team.

Learn More →

Extensions of time and liquidated damages in construction contracts in England and Wales

Extensions of time and liquidated damages in construction contracts in England and Wales Purpose – The purpose of this paper is to examine the relationship between extensions of time and payment of liquidated damages under construction contracts in English law. Design/methodology/approach – This paper sets out the law relating to granting extensions of time and liquidated damages and examines the effect of one upon the other. The JCT form of contract is used as an example, although it is submitted that the position is the same under other forms of contract. Case law is examined to illuminate the judicial approach and highlight inconsistencies, and consideration is given to the position in other jurisdictions. Findings – This paper examines the effect of delaying events in particular circumstances, including where time is “at large”, sectional completion, partial possession, set‐off of liquidated damages and liquidated damages after termination of the contract. Particular attention is paid to concurrent and sequential delays; where both parties are at fault, it may be appropriate to deny the employer any entitlement to liquidated damages and deny the contractor any entitlement to loss and expense. Practical implications – An understanding of the effect that delaying events have upon the contractor's right to an extension of time and the employer's entitlement to liquidated damages is critical for successful project completion. This relationship is not always straightforward and judicial approach is not always consistent. Clarification is required as to the effect of sequential delays. Originality/value – This paper is of value to researchers and practitioners in establishing the legal position in an area that is often complex and obscure. http://www.deepdyve.com/assets/images/DeepDyve-Logo-lg.png International Journal of Law in the Built Environment Emerald Publishing

Extensions of time and liquidated damages in construction contracts in England and Wales

Download PDF
16 pages

Loading next page...
 
/lp/emerald-publishing/extensions-of-time-and-liquidated-damages-in-construction-contracts-in-QBfSiKHehB
Publisher
Emerald Publishing
Copyright
Copyright © 2012 Emerald Group Publishing Limited. All rights reserved.
ISSN
1756-1450
DOI
10.1108/17561451211211750
Publisher site
See Article on Publisher Site

Abstract

Purpose – The purpose of this paper is to examine the relationship between extensions of time and payment of liquidated damages under construction contracts in English law. Design/methodology/approach – This paper sets out the law relating to granting extensions of time and liquidated damages and examines the effect of one upon the other. The JCT form of contract is used as an example, although it is submitted that the position is the same under other forms of contract. Case law is examined to illuminate the judicial approach and highlight inconsistencies, and consideration is given to the position in other jurisdictions. Findings – This paper examines the effect of delaying events in particular circumstances, including where time is “at large”, sectional completion, partial possession, set‐off of liquidated damages and liquidated damages after termination of the contract. Particular attention is paid to concurrent and sequential delays; where both parties are at fault, it may be appropriate to deny the employer any entitlement to liquidated damages and deny the contractor any entitlement to loss and expense. Practical implications – An understanding of the effect that delaying events have upon the contractor's right to an extension of time and the employer's entitlement to liquidated damages is critical for successful project completion. This relationship is not always straightforward and judicial approach is not always consistent. Clarification is required as to the effect of sequential delays. Originality/value – This paper is of value to researchers and practitioners in establishing the legal position in an area that is often complex and obscure.

Journal

International Journal of Law in the Built Environment – Emerald Publishing

Published: Apr 13, 2012

Keywords: England; Wales; Construction industry; Contracts; Law; Construction contracts; Delay; Concurrency; Liquidated damages

References

  • Keating on Construction Contracts
    Furst, S.; Ramsey, V.
  • Standard Building Contract with Approximate Quantities, Revision 2
    Joint Contracts Tribunal Limited
  • Apportionment and the common law: has City Inn got it wrong?
    McAdam, B.
  • Common sense wins out
    Patterson, L.
  • Society of Construction Law Delay and Disruption Protocol
    Society of Construction Law